1. Warranty on kitchen furniture
Keukendepot Bonaire provides a 5-year warranty on kitchen cabinets, hinges and drawer systems, starting from the delivery date. This warranty covers manufacturing and material defects under normal household use.
2. Warranty on appliances
All supplied appliances carry a 1-year manufacturer’s warranty, unless the manufacturer provides a longer warranty period. Warranty service is handled according to the manufacturer’s terms through the designated service partner.
3. Warranty condition (installation)
The warranty on kitchen furniture and appliances applies only when installation and connections are performed by an installer appointed by Keukendepot Bonaire.
4. Existing connections and responsibility
Existing water, drainage, electrical and gas connections are the responsibility of the contractor or homeowner. If these connections are unsuitable or unsafe and are not adjusted, any resulting damage is not covered under warranty.
5. Water and moisture damage
The warranty is void in case of damage caused by leakage, incorrect connections, high water pressure, structural defects or flooding.
6. Handover and reporting obligation
At handover, the kitchen is inspected together with the customer using the completion checklist. By signing the handover form, the customer confirms the kitchen has been received in good condition. Visible defects must be reported at handover. Hidden defects must be reported in writing within 7 days after discovery.
7. Service and resolution
Within the warranty period, Keukendepot Bonaire may, at its discretion, repair or replace parts, perform technical repairs, or provide an appropriate solution. The warranty does not cover consequential or indirect damages.
Delivery terms
In addition to the quote itself, the following terms apply to the delivery of this kitchen.
1. Delivery
Keukendepot Bonaire supplies the kitchen materials as specified in this quote and the accompanying specification and will make every effort to deliver within the delivery time stated in the quote.
2. Storage costs
If, at the customer’s request, the kitchen is not taken delivery of within 30 days after the agreed delivery date, Keukendepot Bonaire charges storage costs of USD 100.00 per month (or part of a month), starting on the 31st day after the agreed delivery date. Storage costs are paid before delivery, unless agreed otherwise.
3. Force majeure
In the event of force majeure, including natural disasters, war, strikes, government measures and transport or supplier delays beyond the control of the parties, neither party is liable for any resulting delay or failure to perform.
4. Governing law and disputes
This agreement is governed by the law applicable in the Caribbean Netherlands (Bonaire). Disputes are submitted to the Court of First Instance of Bonaire, Sint Eustatius and Saba, sitting in Bonaire.
Questions about the warranty? E-mail kitchenbon@building-depot.net.